Learn About the Law
Get help with your legal needs
FindLaw’s Learn About the Law features thousands of informational articles to help you understand your options. And if you’re ready to hire an attorney, find one in your area who can help.
Current as of October 02, 2022 | Updated by FindLaw Staff
As prescribed in 511.504, insert the following clause:
Time Extensions (Mar 2019)FAR 52.211–13, Time Extensions, is supplemented as follows:
(a) If the Contractor requests an extension of the time for substantial completion, the Contractor shall base its request on an analysis of time impact using the project schedule as its baseline, and shall propose as a new substantial completion date to account for the impact. The Contractor shall submit a written request to the Contracting Officer setting forth facts and analysis in sufficient detail to enable the Contracting Officer to evaluate the Contractor's entitlement to an extension of time.
(b) The Contractor shall only be entitled to an extension of time to the extent that—
(1) Substantial completion of the work is delayed by causes for which the Contractor is not responsible under this contract; and
(2) The actual or projected substantial completion date is later than the date required by this contract for substantial completion.
(c) The Contractor shall not be entitled to an extension of time if the Contractor has not updated the project schedule in accordance with the contract.
(d) The Government shall not be liable for any costs to mitigate time impacts incurred by the Contractor that occur less than 30 calendar days after the date the Contractor submits a request for extension of time in compliance with this clause.
(End of clause)
Cite this article: FindLaw.com - Code of Federal Regulations Title 48. Federal Acquisition Regulations System 48.52.211-13 552.211–13 Time Extensions - last updated October 02, 2022 | https://codes.findlaw.com/cfr/title-48-federal-acquisition-regulations-system/cfr-48-552-211-13/
FindLaw Codes may not reflect the most recent version of the law in your jurisdiction. Please verify the status of the code you are researching with the state legislature or via Westlaw before relying on it for your legal needs.
A free source of state and federal court opinions, state laws, and the United States Code. For more information about the legal concepts addressed by these cases and statutes, visit FindLaw's Learn About the Law.
Get help with your legal needs
FindLaw’s Learn About the Law features thousands of informational articles to help you understand your options. And if you’re ready to hire an attorney, find one in your area who can help.
Search our directory by legal issue
Enter information in one or both fields (Required)