Skip to main content
Find a Lawyer

Code of Federal Regulations Title 48. Federal Acquisition Regulations System 48.532.904 Determining payment due dates

Current as of January 02, 2025 | Updated by Findlaw Staff

Payment due dates for construction contracts are addressed at FAR 32.904(d). The following procedures apply to construction and building service contracts:

(a) The amount of final payment must include, as appropriate, deductions to cover any of the following:

(1) Liquidated damages for late completion.

(2) Liquidated damages for labor violations.

(3) Amounts withheld for improper payment of labor wages.

(4) The amount of unilateral change orders covering defects and omissions.

(5) The agreed-upon dollar amount in a Deficiency Report, which is included in all applicable Operation and Maintenance (O & M) service contracts.

(b) When the contract is for the performance of building services, the contracting officer shall include the clause at 552.232–72, Final Payment Under Building Services Contracts.

Previous Part of Code Next Part of Code
Back to Chapter List

Cite this article: FindLaw.com - Code of Federal Regulations Title 48. Federal Acquisition Regulations System 48.532.904 Determining payment due dates - last updated January 02, 2025 | https://codes.findlaw.com/cfr/title-48-federal-acquisition-regulations-system/cfr-48-532-904/

FindLaw Codes may not reflect the most recent version of the law in your jurisdiction. Please verify the status of the code you are researching with the state legislature before relying on it for your legal needs.

Was this helpful?

Welcome to FindLaw's Cases & Codes

A free source of state and federal court opinions, state laws, and the United States Code. For more information about the legal concepts addressed by these cases and statutes, visit FindLaw’s Learn About the Law.

Go to Learn About the Law

Latest Blog Posts

For Legal Professionals

Learn About The Law

Get help with your legal needs

FindLaw’s Learn About the Law features thousands of informational articles to help you understand your options. And if you’re ready to hire an attorney, find one in your area who can help.

Go to Learn About the Law

Need to Find an Attorney?

Search our directory by legal issue

Enter information in one or both fields (Required)

Copied to clipboard