Skip to main content
Find a Lawyer

Code of Federal Regulations Title 48. Federal Acquisition Regulations System 48.42.1305 Contract clauses

Current as of January 02, 2025 | Updated by Findlaw Staff

(a) The contracting officer shall insert the clause at 52.242–14, Suspension of Work, in solicitations and contracts when a fixed-price construction or architect-engineer contract is contemplated.

(b)(1) The contracting officer may, when contracting by negotiation, insert the clause at 52.242–15, Stop–Work Order, in solicitations and contracts for supplies, services, or research and development.

(2) If a cost-reimbursement contract is contemplated, the contracting officer shall use the clause with its Alternate I.

(c) The contracting officer shall insert the clause at 52.242–17, Government Delay of Work, in solicitations and contracts when a fixed-price contract is contemplated for supplies other than commercial or modified-commercial items. The clause use is optional when a fixed-price contract is contemplated for services, or for supplies that are commercial or modified-commercial items.

(d) [Reserved]

Previous Part of Code Next Part of Code
Back to Chapter List

Cite this article: FindLaw.com - Code of Federal Regulations Title 48. Federal Acquisition Regulations System 48.42.1305 Contract clauses - last updated January 02, 2025 | https://codes.findlaw.com/cfr/title-48-federal-acquisition-regulations-system/cfr-48-42-1305/

FindLaw Codes may not reflect the most recent version of the law in your jurisdiction. Please verify the status of the code you are researching with the state legislature before relying on it for your legal needs.

Was this helpful?

Welcome to FindLaw's Cases & Codes

A free source of state and federal court opinions, state laws, and the United States Code. For more information about the legal concepts addressed by these cases and statutes, visit FindLaw’s Learn About the Law.

Go to Learn About the Law

Latest Blog Posts

For Legal Professionals

Learn About The Law

Get help with your legal needs

FindLaw’s Learn About the Law features thousands of informational articles to help you understand your options. And if you’re ready to hire an attorney, find one in your area who can help.

Go to Learn About the Law

Need to Find an Attorney?

Search our directory by legal issue

Enter information in one or both fields (Required)

Copied to clipboard