Skip to main content
Find a Lawyer

Code of Federal Regulations Title 18. Conservation of Power and Water Resources § 18.1308.24 Undue delay in Contracting Officer's decision

Current as of January 02, 2025 | Updated by Findlaw Staff

(a) If there is an undue delay by a Contracting Officer in issuing a decision on a claim, the Contractor may request the Chairman to direct the Contracting Officer to issue a decision within a specified period of time.

(b) A request under this section shall:

(1) Be in writing;

(2) State the date on which the claim was submitted to the Contracting Officer.

(3) State the date suggested for issuance of a decision by the Contracting Officer.

(c) TVA may reply to a motion under this section within 5 days after its receipt.

(d) The Chairman shall issue a written decision on the request. If granted, the decision shall specify the date by which the Contracting Officer's decision is to be rendered, and a copy shall be served on the Contracting Officer.

Previous Part of Code Next Part of Code
Back to Chapter List

Cite this article: FindLaw.com - Code of Federal Regulations Title 18. Conservation of Power and Water Resources § 18.1308.24 Undue delay in Contracting Officer's decision - last updated January 02, 2025 | https://codes.findlaw.com/cfr/title-18-conservation-of-power-and-water-resources/cfr-sect-18-1308-24/

FindLaw Codes may not reflect the most recent version of the law in your jurisdiction. Please verify the status of the code you are researching with the state legislature before relying on it for your legal needs.

Was this helpful?

Welcome to FindLaw's Cases & Codes

A free source of state and federal court opinions, state laws, and the United States Code. For more information about the legal concepts addressed by these cases and statutes, visit FindLaw’s Learn About the Law.

Go to Learn About the Law

Latest Blog Posts

For Legal Professionals

Learn About The Law

Get help with your legal needs

FindLaw’s Learn About the Law features thousands of informational articles to help you understand your options. And if you’re ready to hire an attorney, find one in your area who can help.

Go to Learn About the Law

Need to Find an Attorney?

Search our directory by legal issue

Enter information in one or both fields (Required)

Copied to clipboard