(a) In all actions in which the court has granted an injunction sought by any plaintiff
to enjoin a construction project which has received all legally required licenses
and permits, the defendant may apply to the court by noticed motion for an order requiring
the plaintiff to furnish an undertaking as security for costs and any damages that
may be incurred by the defendant by the conclusion of the action or proceeding as
the result of a delay in the construction of the project. The motion shall be made on the grounds that there is no reasonable possibility
that the plaintiff will obtain a judgment against the moving defendant and that the
plaintiff will not suffer undue economic hardship by filing the undertaking.
(b) If the court, after hearing, determines that the grounds for the motion have been
established, the court shall order that the plaintiff file the undertaking in an amount
specified in the court's order as security for costs and damages of the defendant. The liability of the plaintiff pursuant to this section for the costs and damages
of the defendant shall not exceed five hundred thousand dollars ($500,000).
(c) As used in this section, a construction project includes, but is not restricted
to, the construction, surveying, design, specifications, alteration, repair, improvement,
maintenance, removal, or demolition of any building, highway, road, parking facility,
bridge, railroad, airport, pier or dock, excavation or other structure, development
or other improvement to real or personal property.
FindLaw Codes may not reflect the most recent version of the law in your jurisdiction. Please verify the status of the code you are researching with the state legislature or via Westlaw before relying on it for your legal needs.
Was this helpful?
Response sent, thank you
Welcome to FindLaw's Cases & Codes
A free source of state and federal court opinions, state laws, and the United States Code. For more information about the legal concepts addressed by these cases and statutes, visit FindLaw's Learn About the Law.